Vincent LEFEUVRE
Since 2025, Vincent LEFEUVRE, Technical Director, has been working in the Paris office of DIALES as an expert witness on international construction issues. With over 25 years' professional experience in international construction projects, he specialises in the management and prevention of disputes.
As a recognised expert in his field, Vincent is regularly called upon to testify independently about his work before arbitral or judicial tribunals and also to provide strategic support to his clients during amicable dispute resolution proceedings, always with a strong exposure to oral or written defence of his positions.
Over the years, he has acquired expertise in a wide range of construction sectors: rail (signalling, rolling stock and infrastructure), oil/gas, chemicals, energy, civil aviation, automotive and real estate assisting his clients in their strategic approach to defending their interests in various contexts. : Expertise and Expert Determination, Expert Testimony, Delicate Negotiations, Risk Analyses, Situation Audits of construction projects in the execution phase, on their Contractual, Time impacts, Quantum and Technical aspects.
He also participates in a number of think tanks and training programmes.
PAW Events
Current edition
Monday 23 March 2026
16:30 - 18:30
Projets de construction : retards concomitants, face à l’incertitude jurisprudentielle (CMAP/Diales)
Sign up
array:22 [
"__path" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/wp/wp-content/uploads/cache/c84ebf1432a129894c6a5ed11ec848552cf558ba.php"
"__data" => array:20 [
"__env" => Illuminate\View\Factory {#2419
#engines: Illuminate\View\Engines\EngineResolver {#2411
#resolvers: array:3 [
"file" => Closure() {#2412
class: "Illuminate\View\ViewServiceProvider"
this: Illuminate\View\ViewServiceProvider {#2406 …}
}
"php" => Closure() {#2413
class: "Illuminate\View\ViewServiceProvider"
this: Illuminate\View\ViewServiceProvider {#2406 …}
}
"blade" => Closure() {#2414
class: "Illuminate\View\ViewServiceProvider"
this: Illuminate\View\ViewServiceProvider {#2406 …}
}
]
#resolved: array:1 [
"blade" => Illuminate\View\Engines\CompilerEngine {#4211
#files: Illuminate\Filesystem\Filesystem {#2416}
#compiler: Illuminate\View\Compilers\BladeCompiler {#2420
#files: Illuminate\Filesystem\Filesystem {#2416}
#cachePath: "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/wp/wp-content/uploads/cache"
#extensions: []
#customDirectives: array:4 [
"asset" => array:2 [
0 => Magina\StarterTheme\Template\Directives {#2357}
1 => "asset"
]
"shortcode" => array:2 [
0 => Magina\StarterTheme\Template\Directives {#2357}
1 => "shortcode"
]
"debug" => array:2 [
0 => Magina\StarterTheme\Template\Directives {#2357}
1 => "debug"
]
"svg" => array:2 [
0 => Magina\StarterTheme\Template\Directives {#2357}
1 => "svg"
]
]
#conditions: []
#precompilers: []
#path: null
#compilers: array:3 [
0 => "Extensions"
1 => "Statements"
2 => "Echos"
]
#rawTags: array:2 [
0 => "{!!"
1 => "!!}"
]
#contentTags: array:2 [
0 => "{{"
1 => "}}"
]
#escapedTags: array:2 [
0 => "{{{"
1 => "}}}"
]
#echoFormat: "e(%s)"
#footer: []
#rawBlocks: []
#classComponentAliases: array:1 [
"dynamic-component" => "Illuminate\View\DynamicComponent"
]
#classComponentNamespaces: []
#compilesComponentTags: true
#firstCaseInSwitch: true
#echoHandlers: []
-encodingOptions: 15
#lastSection: null
#forElseCounter: 0
}
#lastCompiled: array:3 [
0 => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/author.blade.php"
1 => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/layouts/app.blade.php"
2 => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/structs/footer.blade.php"
]
}
]
}
#finder: Illuminate\View\FileViewFinder {#2415
#files: Illuminate\Filesystem\Filesystem {#2416}
#paths: array:1 [
0 => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views"
]
#views: array:12 [
"author" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/author.blade.php"
"partials.expanding-avatar" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/partials/expanding-avatar.blade.php"
"partials.item-event" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/partials/item-event.blade.php"
"partials.event-format" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/partials/event-format.blade.php"
"blocks.calendar-cta-banner" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/blocks/calendar-cta-banner.blade.php"
"layouts.app" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/layouts/app.blade.php"
"structs.head" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/structs/head.blade.php"
"structs.header" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/structs/header.blade.php"
"partials.notices" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/partials/notices.blade.php"
"partials.breadcrumbs" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/partials/breadcrumbs.blade.php"
"structs.footer" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/structs/footer.blade.php"
"partials.nav-social" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/src/themes/paw/resources/views/partials/nav-social.blade.php"
]
#hints: []
#extensions: array:4 [
0 => "blade.php"
1 => "php"
2 => "css"
3 => "html"
]
}
#events: Illuminate\Events\Dispatcher {#2417
#container: Illuminate\Container\Container {#2418
#resolved: []
#bindings: []
#methodBindings: []
#instances: []
#scopedInstances: []
#aliases: []
#abstractAliases: []
#extenders: []
#tags: []
#buildStack: []
#with: []
+contextual: []
#reboundCallbacks: []
#globalBeforeResolvingCallbacks: []
#globalResolvingCallbacks: []
#globalAfterResolvingCallbacks: []
#beforeResolvingCallbacks: []
#resolvingCallbacks: []
#afterResolvingCallbacks: []
}
#listeners: []
#wildcards: []
#wildcardsCache: array:24 [
"creating: author" => []
"composing: author" => []
"creating: partials.expanding-avatar" => []
"composing: partials.expanding-avatar" => []
"creating: partials.item-event" => []
"composing: partials.item-event" => []
"creating: partials.event-format" => []
"composing: partials.event-format" => []
"creating: blocks.calendar-cta-banner" => []
"composing: blocks.calendar-cta-banner" => []
"creating: layouts.app" => []
"composing: layouts.app" => []
"creating: structs.head" => []
"composing: structs.head" => []
"creating: structs.header" => []
"composing: structs.header" => []
"creating: partials.notices" => []
"composing: partials.notices" => []
"creating: partials.breadcrumbs" => []
"composing: partials.breadcrumbs" => []
"creating: structs.footer" => []
"composing: structs.footer" => []
"creating: partials.nav-social" => []
"composing: partials.nav-social" => []
]
#queueResolver: null
}
#container: Illuminate\Container\Container {#2401
#resolved: array:7 [
"view.engine.resolver" => true
"files" => true
"config" => true
"view.finder" => true
"events" => true
"view" => true
"blade.compiler" => true
]
#bindings: array:7 [
"files" => array:2 [
"concrete" => Closure() {#2403
class: "Jenssegers\Blade\Blade"
this: Jenssegers\Blade\Blade {#2402 …}
}
"shared" => true
]
"events" => array:2 [
"concrete" => Closure() {#2404
class: "Jenssegers\Blade\Blade"
this: Jenssegers\Blade\Blade {#2402 …}
}
"shared" => true
]
"config" => array:2 [
"concrete" => Closure() {#2405
class: "Jenssegers\Blade\Blade"
this: Jenssegers\Blade\Blade {#2402 …}
use: {
$viewPaths: array:1 [
0 => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/wp/wp-content/themes/paw/resources/views"
]
$cachePath: "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/wp/wp-content/uploads/cache"
}
}
"shared" => true
]
"view" => array:2 [
"concrete" => Closure($app) {#2407
class: "Illuminate\View\ViewServiceProvider"
this: Illuminate\View\ViewServiceProvider {#2406 …}
}
"shared" => true
]
"view.finder" => array:2 [
"concrete" => Closure($app) {#2408
class: "Illuminate\View\ViewServiceProvider"
this: Illuminate\View\ViewServiceProvider {#2406 …}
}
"shared" => false
]
"blade.compiler" => array:2 [
"concrete" => Closure($app) {#2409
class: "Illuminate\View\ViewServiceProvider"
this: Illuminate\View\ViewServiceProvider {#2406 …}
}
"shared" => true
]
"view.engine.resolver" => array:2 [
"concrete" => Closure() {#2410
class: "Illuminate\View\ViewServiceProvider"
this: Illuminate\View\ViewServiceProvider {#2406 …}
}
"shared" => true
]
]
#methodBindings: []
#instances: array:6 [
"view.engine.resolver" => Illuminate\View\Engines\EngineResolver {#2411}
"files" => Illuminate\Filesystem\Filesystem {#2416}
"config" => array:2 [
"view.paths" => array:1 [
0 => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/wp/wp-content/themes/paw/resources/views"
]
"view.compiled" => "/var/www/vhosts/parisarbitrationweek.preprod.online/httpdocs/wp/wp-content/uploads/cache"
]
"events" => Illuminate\Events\Dispatcher {#2417}
"view" => Illuminate\View\Factory {#2419}
"blade.compiler" => Illuminate\View\Compilers\BladeCompiler {#2420}
]
#scopedInstances: []
#aliases: []
#abstractAliases: []
#extenders: []
#tags: []
#buildStack: []
#with: []
+contextual: []
#reboundCallbacks: []
#globalBeforeResolvingCallbacks: []
#globalResolvingCallbacks: []
#globalAfterResolvingCallbacks: []
#beforeResolvingCallbacks: []
#resolvingCallbacks: []
#afterResolvingCallbacks: []
}
#shared: array:2 [
"__env" => Illuminate\View\Factory {#2419}
"app" => Illuminate\Container\Container {#2401}
]
#extensions: array:4 [
"blade.php" => "blade"
"php" => "php"
"css" => "file"
"html" => "file"
]
#composers: []
#renderCount: 3
#renderedOnce: []
#componentStack: []
#componentData: []
#currentComponentData: []
#slots: []
#slotStack: []
#sections: array:1 [
"content" => """
<div class="wrapper">\n
<h1>Vincent LEFEUVRE</h1>\n
<hr />\n
<div class="infos">\n
<div class="job">\n
Delay & Quantum Expert\n
</div>\n
<div class="partner-company">\n
<a href="https://parisarbitrationweek.preprod.online/partner/diales/">\n
<img src="https://parisarbitrationweek.preprod.online/wp-content/uploads/2025/02/diales-new-logo_no-tagline-01-1-2087x875_1209.png" class="partner-logo" alt="Diales">\n
</a>\n
</div>\n
</div>\n
<hr />\n
\n
<div class="author-columns">\n
<div class="column-left">\n
<p>Since 2025, Vincent LEFEUVRE, Technical Director, has been working in the Paris office of DIALES as an expert witness on international construction issues. With over 25 years' professional experience in international construction projects, he specialises in the management and prevention of disputes.<br />\n
As a recognised expert in his field, Vincent is regularly called upon to testify independently about his work before arbitral or judicial tribunals and also to provide strategic support to his clients during amicable dispute resolution proceedings, always with a strong exposure to oral or written defence of his positions.<br />\n
Over the years, he has acquired expertise in a wide range of construction sectors: rail (signalling, rolling stock and infrastructure), oil/gas, chemicals, energy, civil aviation, automotive and real estate assisting his clients in their strategic approach to defending their interests in various contexts. : Expertise and Expert Determination, Expert Testimony, Delicate Negotiations, Risk Analyses, Situation Audits of construction projects in the execution phase, on their Contractual, Time impacts, Quantum and Technical aspects.<br />\n
He also participates in a number of think tanks and training programmes.</p>\n
\n
<div class="socials">\n
<a href="https://www.linkedin.com/in/vincent-lefeuvre-0a537a38/" class="mr-3" target="_blank">\n
<svg xmlns="http://www.w3.org/2000/svg" width="37.63" height="37.63" viewBox="0 0 37.63 37.63">\n
<g transform="translate(-249 -866.717)">\n
<path d="M37.63,18.879A18.815,18.815,0,1,1,18.815.064,18.815,18.815,0,0,1,37.63,18.879" transform="translate(249 866.653)" fill="#7593FF"/>\n
<rect width="3.03" height="9.111" transform="translate(261.224 881.1)" fill="#fff"/>\n
<path d="M13.739,13.2h-.02a1.579,1.579,0,1,1,.04-3.15,1.58,1.58,0,1,1-.02,3.15" transform="translate(249 866.653)" fill="#fff"/>\n
<path d="M26.176,23.558H23.147V18.684c0-1.225-.438-2.062-1.535-2.062a1.661,1.661,0,0,0-1.554,1.109,2.067,2.067,0,0,0-.1.739v5.088H16.93s.039-8.257,0-9.111h3.028v1.29a3.007,3.007,0,0,1,2.73-1.5c1.993,0,3.488,1.3,3.488,4.1Z" transform="translate(249 866.653)" fill="#fff"/>\n
</g>\n
</svg>\n
</a> \n
</div>\n
</div>\n
<div class="column-right ">\n
<div class="expanding-avatar">\n
<div class="expanding-avatar-container">\n
<figure class="expanding-avatar-figure">\n
\n
<img src="https://parisarbitrationweek.preprod.online/wp-content/uploads/2026/02/1689673994472.jpg" alt="Vincent LEFEUVRE"/>\n
\n
<div class="expanding-avatar-corner expanding-avatar-corner--top-left">\n
<svg width="50" height="50" viewBox="0 0 50 50" fill="none" xmlns="http://www.w3.org/2000/svg">\n
<path d="M1.04061 49.4195C0.466973 49.4195 0.00195308 48.9544 0.00195312 48.3808L0.00195697 2.7194C0.00195705 1.794 1.12074 1.3306 1.77506 1.9849L47.4365 47.6464C48.0908 48.3007 47.6274 49.4195 46.702 49.4195H1.04061Z" fill="#0128FF"/>\n
</svg>\n
</div>\n
<div class="expanding-avatar-corner expanding-avatar-corner--top-right">\n
<svg width="50" height="50" viewBox="0 0 50 50" fill="none" xmlns="http://www.w3.org/2000/svg">\n
<path d="M48.3779 0C48.9516 0 49.4166 0.465031 49.4166 1.03867L49.4166 46.7001C49.4166 47.6254 48.2978 48.0888 47.6435 47.4345L1.9821 1.7731C1.3278 1.11878 1.7912 0 2.7165 0L48.3779 0Z" fill="#0128FF"/>\n
</svg>\n
</div>\n
<div class="expanding-avatar-corner expanding-avatar-corner--bottom-right">\n
<svg width="50" height="50" viewBox="0 0 50 50" fill="none" xmlns="http://www.w3.org/2000/svg">\n
<path d="M49.4185 48.3808C49.4185 48.9544 48.9535 49.4194 48.3799 49.4194H2.7185C1.7931 49.4194 1.3297 48.3007 1.984 47.6463L47.6454 1.9849C48.2997 1.3306 49.4185 1.794 49.4185 2.7194V48.3808Z" fill="#0128FF"/>\n
</svg>\n
</div>\n
<div class="expanding-avatar-corner expanding-avatar-corner--bottom-left">\n
<svg width="50" height="50" viewBox="0 0 50 50" fill="none" xmlns="http://www.w3.org/2000/svg">\n
<path d="M0 1.03865C0 0.46502 0.465027 0 1.03866 0L46.7001 0C47.6254 0 48.0888 1.11879 47.4345 1.7731L1.7731 47.4345C1.11878 48.0888 0 47.6254 0 46.7001L0 1.03865Z" fill="#0128FF"/>\n
</svg>\n
</div>\n
</figure>\n
</div>\n
</div> </div>\n
</div>\n
</div>\n
\n
\n
<div class="wrapper user-events">\n
<h3>PAW Events</h3>\n
\n
<section class="events period-current">\n
<h4>Current edition</h4>\n
<div \n
class="item event "\n
data-id="41365"\n
data-partner="["4078"]"\n
data-speakers="["16847","2552","16855","15446"]"\n
data-themes="[8]"\n
data-regions="[34,33]"\n
data-format="in_person"\n
data-schedule="afternoon"\n
data-category="academic"\n
data-date="2026-03-23"\n
data-hours="16:30 - 18:30"\n
data-video=""\n
data-pictures=""\n
data-publication=""\n
data-geoloc="48.8694846,2.2933583"\n
> <div class="inside" data-id="41365">\n
<div class="event-date">\n
<span class="day">\n
Mon. <b>23</b>\n
Mar.\n
</span>\n
<span class="year">2026</span>\n
</div>\n
<div class="event-details">\n
<a href="https://parisarbitrationweek.preprod.online/event/diales-2026-41365/" class="event-title">\n
Projets de construction : retards concomitants, face à l’incertitude jurisprudentielle (CMAP/Diales)\n
</a>\n
<div class="event-partners">\n
<a href="https://parisarbitrationweek.preprod.online/partner/diales/" class="partner">Diales</a>\n
</div>\n
<div class="event-themes">\n
<span class="theme">#Construction</span>\n
<span class="region">#Africa</span>\n
<span class="region">#Europe</span>\n
</div>\n
</div>\n
<div class="event-metas">\n
\n
\n
<div class="event-format">\n
<div class="term">\n
<svg xmlns="http://www.w3.org/2000/svg" width="15.036" height="7.786" viewBox="0 0 15.036 7.786">\r\n
<path d="M7.708,7.328a.269.269,0,0,1,0,.38L.459,14.957A.269.269,0,0,1,0,14.767V.269A.269.269,0,0,1,.459.079Z" transform="translate(15.036) rotate(90)" fill="currentColor"/>\r\n
</svg>\r\n
\n
IN PERSON\n
</div>\n
</div>\n
\n
</div>\n
\n
<div class="event-ressources">\n
<span class="closed">CLOSED</span>\n
</div>\n
</div>\n
\n
\n
<div class="map-det is-hidden">\n
<div class="date">\n
<div class="day">\n
Monday <b>23</b> March 2026\n
</div>\n
<div class="hours my-3">\n
16:30 - 18:30\n
</div>\n
</div>\n
<div class="title">Projets de construction : retards concomitants, face à l’incertitude jurisprudentielle (CMAP/Diales)</div>\n
<div class="my-3">\n
<div class="partner">Diales</div>\n
</div>\n
<div class="is-flex mb-3">\n
<span class="is-flex mr-5">\n
<div class="event-format">\n
<div class="term">\n
<svg xmlns="http://www.w3.org/2000/svg" width="15.036" height="7.786" viewBox="0 0 15.036 7.786">\r\n
<path d="M7.708,7.328a.269.269,0,0,1,0,.38L.459,14.957A.269.269,0,0,1,0,14.767V.269A.269.269,0,0,1,.459.079Z" transform="translate(15.036) rotate(90)" fill="currentColor"/>\r\n
</svg>\r\n
\n
IN PERSON\n
</div>\n
</div>\n
</span>\n
\n
</div>\n
<div class="event-address">\n
<span>\n
17 rue Dumont d’Urville\n
75116\n
Paris\n
</span>\n
<a href="https://www.google.com/maps/search/?api=1&query=17+rue+Dumont+d’Urville,75116,Paris" target="_blank" class="address-link button is-style-secondary mt-2">\n
<span>How to get there</span>\n
</a>\n
</div>\n
<a href="https://parisarbitrationweek.preprod.online/event/diales-2026-41365/" class="button is-style-primary mt-5">\n
<span>Sign up\n
<i class="paw-icon-arrow"></i>\n
</span>\n
</a>\n
</div>\n
\n
\n
</div> </section>\n
\n
\n
</div>\n
\n
\n
\n
<div class="wrapper">\n
<div class="wp-block-magina-calendar-cta-banner">\n
<div class="calendar-cta-banner aligncompact">\n
<i class="icon-blue-light">\n
<svg width="98" height="98" viewBox="0 0 98 98" fill="none" xmlns="http://www.w3.org/2000/svg">\n
<path d="M95.4912 50.3797C96.3741 50.3797 97.0898 51.0955 97.0898 51.9784L97.0898 93.466C97.0898 94.8903 95.3678 95.6036 94.3607 94.5965L52.8731 53.1088C51.866 52.1017 52.5793 50.3797 54.0035 50.3797L95.4912 50.3797Z" fill="currentColor"/>\n
<path d="M95.4912 0.237034C96.3741 0.237034 97.0898 0.952781 97.0898 1.8357L97.0898 43.3233C97.0898 44.7476 95.3678 45.4609 94.3607 44.4538L52.8731 2.96613C51.866 1.95902 52.5793 0.237031 54.0035 0.237032L95.4912 0.237034Z" fill="currentColor"/>\n
<path d="M45.3476 -2.62386e-05C46.2305 -2.6179e-05 46.9463 0.715721 46.9463 1.59864L46.9463 43.0863C46.9463 44.5105 45.2243 45.2238 44.2172 44.2167L2.72956 2.72907C1.72246 1.72196 2.43573 -2.91323e-05 3.85999 -2.90363e-05L45.3476 -2.62386e-05Z" fill="currentColor"/>\n
<path d="M45.3476 50.1426C46.2305 50.1426 46.9463 50.8583 46.9463 51.7412L46.9463 93.2289C46.9463 94.6531 45.2243 95.3664 44.2172 94.3593L2.72956 52.8716C1.72246 51.8645 2.43573 50.1425 3.85999 50.1425L45.3476 50.1426Z" fill="currentColor"/>\n
</svg>\n
</i>\n
<div class="calendar-cta-content">\n
<div class="calendar-cta-heading">\n
<h3 class="is-style-h2">\n
Don't miss anything\n
</h3>\n
</div>\n
<div class="calendar-cta">\n
<a class="button is-style-primary-white" href="https://parisarbitrationweek.preprod.online/event/" target="_blank" rel="noopener noreferrer">\n
<span>See full calendar\n
<i class="paw-icon-arrow"></i>\n
</span>\n
</a>\n
</div>\n
</div>\n
<i class="icon-blue">\n
<svg width="101" height="101" viewBox="0 0 101 101" fill="none" xmlns="http://www.w3.org/2000/svg">\n
<path d="M99.6526 49.1526C100.397 49.8968 100.397 51.1033 99.6526 51.8474L51.8474 99.6526C51.1032 100.397 49.8967 100.397 49.1526 99.6526L1.34739 51.8474C0.603248 51.1032 0.603249 49.8968 1.34739 49.1526L49.1526 1.34739C49.8968 0.603248 51.1033 0.603248 51.8474 1.34739L99.6526 49.1526Z" fill="currentColor"/>\n
</svg>\n
</i>\n
</div>\n
</div> </div>\n
\n
"""
]
#sectionStack: []
#loopsStack: []
#pushes: []
#prepends: []
#pushStack: []
#translationReplacements: []
}
"app" => Illuminate\Container\Container {#2401}
"override" => "app"
"display_sidebar" => false
"notices" => []
"browser" => null
"displayArchiveStructs" => false
"relatedEdition" => WP_Post {#4155
+ID: 40615
+post_author: "234"
+post_date: "2025-11-17 10:14:18"
+post_date_gmt: "2025-11-17 10:14:18"
+post_content: ""
+post_title: "2026"
+post_excerpt: ""
+post_status: "publish"
+comment_status: "closed"
+ping_status: "closed"
+post_password: ""
+post_name: "2026"
+to_ping: ""
+pinged: ""
+post_modified: "2026-02-12 11:08:32"
+post_modified_gmt: "2026-02-12 11:08:32"
+post_content_filtered: ""
+post_parent: 0
+guid: "https://parisarbitrationweek.preprod.online/?post_type=edition&p=40615"
+menu_order: 0
+post_type: "edition"
+post_mime_type: ""
+comment_count: "0"
+filter: "raw"
+"isCurrent": "on"
+"num": "2026"
+"dateOpeningRegister": "2026-01-05"
+"datePawEventRegister": "2026-02-20"
+"dateStart": "2026-03-23"
+"dateEnd": "2026-03-27"
+"committeeImage": ""
+"committeeDescription": ""
+"emailHeader": "https://parisarbitrationweek.preprod.online/wp-content/uploads/2025/11/header-paw2026-v2.png"
+"stats": {#4154
+"eventsCount": ""
+"partnersCount": ""
+"participantsCount": ""
+"registrationsCount": ""
+"satisfaction": ""
}
}
"edition_dates" => "23 - 27 March 2026"
"static_pages" => array:9 [
"middle_office" => "89"
"digital_library" => "13219"
"legal_notice" => "955"
"privacy_statement" => "12766"
"contact_us" => "95"
"sign_in" => "424"
"visitor_register" => "40592"
"partner_register" => "28"
"maintenance" => "40491"
]
"user" => WP_User {#4150
+data: {#4151
+"ID": "16847"
+"user_login": "vincent.lefeuvre@diales.com"
+"user_pass": "$wp$2y$10$e/KJoIg6OyYYQVICQbcBLexEj9bjYxXmkuLW5CuaV4s8a7Hfjaqju"
+"user_nicename": "vincent-lefeuvre-16847"
+"user_email": "vincent.lefeuvre@diales.com"
+"user_url": ""
+"user_registered": "2026-02-17 14:39:35"
+"user_activation_key": "1771339176:$generic$hJ8F3GuZx_HBZptWcU-Vpwv8o6tHSxL2ha56LX4H"
+"user_status": "0"
+"display_name": "vincent.lefeuvre@diales.com"
+"review": ""
+"state": "published"
+"first_name": "Vincent"
+"last_name": "LEFEUVRE"
+"full_name": "Vincent LEFEUVRE"
+"civility": "Mr"
+"description": """
Since 2025, Vincent LEFEUVRE, Technical Director, has been working in the Paris office of DIALES as an expert witness on international construction issues. With over 25 years' professional experience in international construction projects, he specialises in the management and prevention of disputes. \r\n
As a recognised expert in his field, Vincent is regularly called upon to testify independently about his work before arbitral or judicial tribunals and also to provide strategic support to his clients during amicable dispute resolution proceedings, always with a strong exposure to oral or written defence of his positions.\r\n
Over the years, he has acquired expertise in a wide range of construction sectors: rail (signalling, rolling stock and infrastructure), oil/gas, chemicals, energy, civil aviation, automotive and real estate assisting his clients in their strategic approach to defending their interests in various contexts. : Expertise and Expert Determination, Expert Testimony, Delicate Negotiations, Risk Analyses, Situation Audits of construction projects in the execution phase, on their Contractual, Time impacts, Quantum and Technical aspects.\r\n
He also participates in a number of think tanks and training programmes.
"""
+"citation": ""
+"citationAuthor": ""
+"company": ""
+"companyID": "4078"
+"job": "Delay & Quantum Expert"
+"status": ""
+"phone": "+33615206427"
+"country": ""
+"city": ""
+"twitter": ""
+"linkedin": "https://www.linkedin.com/in/vincent-lefeuvre-0a537a38/"
+"default_paw_networking": ""
+"avatar": "https://parisarbitrationweek.preprod.online/wp-content/uploads/2026/02/1689673994472.jpg"
+"rang": ""
+"activity": ""
+"themes": ""
+"companyName": "Diales"
+"favorites": []
}
+ID: 16847
+caps: array:1 [
"speaker" => true
]
+cap_key: "wp_capabilities"
+roles: array:1 [
0 => "speaker"
]
+allcaps: array:2 [
"read" => true
"speaker" => true
]
+filter: null
-site_id: 1
}
"currentEvents" => array:1 [
0 => 41365
]
"previousEvents" => []
"partner" => WP_Post {#4583
+ID: 4078
+post_author: "1209"
+post_date: "2026-02-26 14:30:51"
+post_date_gmt: "2026-02-26 14:30:51"
+post_content: """
As a global expert witness and consultancy business, Diales has been providing support and expertise to clients in the construction and engineering industries across the world for over thirty years.\r\n
\r\n
Diales experts offer uncompromised expertise to the legal profession in adjudication, arbitration, litigation and all forms of alternative dispute resolution, including mediation, independent evaluation and dispute avoidance boards. Our expert team also includes accredited Adjudicators, Arbitrators and Mediators.\r\n
\r\n
At the heart of our operations lies our established network of offices around the world, with a knowledgeable and dedicated team experienced in providing support on the most challenging of projects, whether in an expert or advisory capacity. We speak over 25 languages collectively, including Spanish, Arabic and French, and work across the globe – a truly international presence, with local expertise.\r\n
\r\n
Depending on the nature of the dispute, we are able to provide a multi-disciplined team of experts, with broad experience, offering a complete expert service with the benefit of collaboration and enhanced understanding of the issues between the instructed experts\r\n
\r\n
Our skills and knowledge span matters relating to project costs, delays and disruption, project management, construction management, PFI, architecture, civil engineering, structural engineering, mechanical and electrical services, and power and environmental engineering.\r\n
\r\n
The quality and experience of our people is fundamental to our success. Whether your requirement is for initial commercial and programming support, technical advice or dedicated training at the outset of a project, or dispute management and testifying expert witness services during or at the end of a project, our team can assist.\r\n
\r\n
We have experience in projects across the industry, including building, transportation and infrastructure, energy, process and industrial, oil and gas, shipbuilding and marine, and mining..\r\n
\r\n
Combined with our in-house IT expertise that allows us to work remotely and handle large volumes of data, our highly qualified team is dedicated to delivering exceptional services on time and within budget.\r\n
\r\n
We create innovative and flexible solutions for our clients at every opportunity, with our company values of innovation, integrity and transparency at the core of what we do.\r\n
\r\n
Getting the right expert is an essential appointment. Wherever you are in the world, no matter what the sector or size of the dispute, we have the expertise.\r\n
\r\n
\r\n
Key Contacts: David Coyne, Natasha Fortune, & Vincent Lefeuvre, Paris, France
"""
+post_title: "Diales"
+post_excerpt: ""
+post_status: "publish"
+comment_status: "closed"
+ping_status: "closed"
+post_password: ""
+post_name: "diales"
+to_ping: ""
+pinged: ""
+post_modified: "2026-02-26 14:30:51"
+post_modified_gmt: "2026-02-26 14:30:51"
+post_content_filtered: ""
+post_parent: 0
+guid: "https://parisarbitrationweek.preprod.online/partner/diales/"
+menu_order: 0
+post_type: "partner"
+post_mime_type: ""
+comment_count: "0"
+filter: "raw"
+"review": ""
+"state": "online"
+"paymentCustomer": ""
+"paymentURL": ""
+"paymentID": ""
+"paymentStatus": "valid"
+"paymentInvoiceNumber": "11"
+"paymentInvoiceDate": "02/12/2025"
+"category": "expert_firm"
+"type": "paying_big"
+"logos": array:1 [
0 => "https://parisarbitrationweek.preprod.online/wp-content/uploads/2025/02/diales-new-logo_no-tagline-01-1-2087x875_1209.png"
]
+"citation": ""
+"citationAuthor": ""
+"website": "https://www.diales.com/"
+"linkedin": "https://www.linkedin.com/company/diales-plc/"
+"twiter": ""
+"contactEmail": "david.coyne@diales.com"
+"address": {#4582
+"street1": "17 Rue Dumont d'Urville, Paris, France"
+"street2": ""
+"street": "17 Rue Dumont d'Urville, Paris, France "
+"postcode": "75116"
+"city": "Paris"
+"country": "France"
+"legal_entity": ""
+"billing_street1": ""
+"billing_street2": ""
+"billing_street": " "
+"billing_postcode": ""
+"billing_city": ""
+"billing_country": ""
}
+"masterUsers": array:1 [
0 => "1209"
]
+"speakerHosts": array:3 [
0 => "8109"
1 => "10369"
2 => "16847"
]
+"speakerGuests": array:22 [
0 => "4934"
1 => "4935"
2 => "4936"
3 => "4938"
4 => "6835"
5 => "6836"
6 => "1375"
7 => "7170"
8 => "7335"
9 => "10475"
10 => "10576"
11 => "10848"
12 => "11789"
13 => "14436"
14 => "14118"
15 => "11282"
16 => "15891"
17 => "6488"
18 => "1611"
19 => "2552"
20 => "16855"
21 => "15446"
]
+"strategic": {#4584
+"lastname": "Coyne"
+"firstname": "David"
+"email": "david.coyne@diales.com"
+"phone": "+33662124733"
+"job": "Construction Delay Expert"
+"civility": "Mr"
}
+"otherContacts": array:6 [
0 => array:7 [
"partner_id" => "4078"
"" => ""
"firstname" => "Javier"
"lastname" => "Sanchez"
"email" => "Javier.Sanchez@diales.com"
"event" => "Opening Cocktail"
"phone" => "+34662016638"
]
1 => array:7 [
"partner_id" => "4078"
"" => ""
"firstname" => "Timo"
"lastname" => "Zinnel"
"email" => "Timo.Zinnel@diales.com"
"event" => "Opening Cocktail"
"phone" => "+491704402842"
]
2 => array:7 [
"partner_id" => "4078"
"" => ""
"firstname" => "David"
"lastname" => "Coyne"
"email" => "david.coyne@diales.com"
"event" => "Closing Cocktail"
"phone" => "+33662124733"
]
3 => array:7 [
"partner_id" => "4078"
"" => ""
"firstname" => "Natasha"
"lastname" => "Fortune"
"email" => "natasha.fortune@diales.com"
"event" => "Closing Cocktail"
"phone" => "+33666168940"
]
4 => array:7 [
"partner_id" => "4078"
"" => ""
"firstname" => "David"
"lastname" => "Coyne"
"email" => "david.coyne@diales.com"
"event" => "In-house Event"
"phone" => "+33666168940"
]
5 => array:7 [
"partner_id" => "4078"
"" => ""
"firstname" => "David"
"lastname" => "Coyne"
"email" => "david.coyne@diales.com"
"event" => "Sustainability Event"
"phone" => "+33662124733"
]
]
+"editions": array:4 [
0 => "40615"
1 => "39376"
2 => "13223"
3 => "13224"
]
+"currentEvents": array:2 [
0 => 41365
1 => 41014
]
}
"link" => "https://parisarbitrationweek.preprod.online/partner/diales/"
"__currentLoopData" => array:1 [
0 => 41365
]
"logo" => "https://parisarbitrationweek.preprod.online/wp-content/uploads/2025/02/diales-new-logo_no-tagline-01-1-2087x875_1209.png"
"loop" => null
"eventID" => 41365
"event" => WP_Post {#4579
+ID: 41365
+post_author: "1209"
+post_date: "2026-03-20 19:19:52"
+post_date_gmt: "2026-03-20 19:19:52"
+post_content: """
Cet événement se déroulera en français. Il se fera en collaboration avec le Centre de Médiation et d'Arbitrage de Paris (CMAP) dont la mission est de prévenir et résoudre efficacement les conflits notamment via la médiation et l'arbitrage.\r\n
\r\n
Rejoignez-nous pour discuter de l'analyse des retards concomitants dans le cadre de projets de construction.\r\n
\r\n
Vincent présentera la notion de retards concomitants, leur définition, les méthodes permettant de les évaluer, ainsi que l'approche dite du « First In Line » qui reflète la position du protocole SCL et les récentes décisions rendues par les tribunaux anglais, notamment dans l'affaire Royal Brompton c. Hammond. Il examinera également les biais et les imprécisions susceptibles d'affecter les résultats de l'analyse retards, notamment le choix des fenêtres de temps, dont l'influence peut être déterminant.\r\n
\r\n
Anne analysera ensuite la manière dont les retards concomitants sont appréhendés et indemnisés dans les principales juridictions.\r\n
Gabriele abordera enfin la jurisprudence relative au partage de la responsabilité en droit français, dans lequel il n'existe pas, à ce jour, de référence spécifiquement adaptée aux problématiques particulières soulevées par les retards concomitants.\r\n
\r\n
Jérémy modérera l'événement.
"""
+post_title: "Projets de construction : retards concomitants, face à l’incertitude jurisprudentielle (CMAP/Diales)"
+post_excerpt: ""
+post_status: "publish"
+comment_status: "closed"
+ping_status: "closed"
+post_password: ""
+post_name: "diales-2026-41365"
+to_ping: ""
+pinged: ""
+post_modified: "2026-03-20 19:19:52"
+post_modified_gmt: "2026-03-20 19:19:52"
+post_content_filtered: ""
+post_parent: 0
+guid: "https://parisarbitrationweek.preprod.online/event/projets-de-construction-retards-concomitants-face-a-lincertitude-jurisprudentielle-cmap-diales/"
+menu_order: 0
+post_type: "event"
+post_mime_type: ""
+comment_count: "0"
+filter: "raw"
+"review": ""
+"state": "closed"
+"themes": array:1 [
0 => WP_Term {#4580
+term_id: 8
+name: "Construction"
+slug: "construction"
+term_group: 0
+term_taxonomy_id: 8
+taxonomy: "theme"
+description: ""
+parent: 0
+count: 72
+filter: "raw"
}
]
+"themeIDs": array:1 [
0 => 8
]
+"regions": array:2 [
0 => WP_Term {#4533
+term_id: 34
+name: "Africa"
+slug: "africa"
+term_group: 0
+term_taxonomy_id: 34
+taxonomy: "region"
+description: ""
+parent: 0
+count: 129
+filter: "raw"
}
1 => WP_Term {#4574
+term_id: 33
+name: "Europe"
+slug: "europe"
+term_group: 0
+term_taxonomy_id: 33
+taxonomy: "region"
+description: ""
+parent: 0
+count: 275
+filter: "raw"
}
]
+"regionIDs": array:2 [
0 => 34
1 => 33
]
+"partnerID": "4078"
+"type": "open"
+"category": "academic"
+"format": "in_person"
+"paw_networking": "on"
+"coHosts": []
+"date": "2026-03-23"
+"startingTimeSlot": "66600"
+"startTime": "16:30"
+"endTime": "18:30"
+"dateOpeningRegister": "2026-01-05"
+"dateLimitRegister": "2026-03-23"
+"showDateOpeningRegister": false
+"isOpenForRegistration": true
+"typeStart": "afternoon"
+"edition": "40615"
+"isCurrent": true
+"registrationType": "paw"
+"externalRegistrationLink": ""
+"ticketsNumber": "60"
+"onlineConfLink": ""
+"hasWaitingList": false
+"cocktail": {#4586
+"desc": ""
+"start": "18:00"
+"end": "19:00"
+"image": ""
}
+"replay": ""
+"photos": ""
+"publication": ""
+"publication_description": ""
+"address": {#4587
+"street": "17 rue Dumont d’Urville"
+"building": "17 (bureaux Diales)"
+"city": "Paris"
+"postcode": "75116"
+"information": ""
+"gps": "48.8694846,2.2933583"
+"maps_query": "17+rue+Dumont+d’Urville,75116,Paris"
}
+"speakerHosts": array:1 [
0 => "16847"
]
+"speakerGuests": array:3 [
0 => "2552"
1 => "16855"
2 => "15446"
]
+"attendeeReminderLastSent": ""
+"attendees": array:75 [
10748 => array:7 [
"userID" => 10748
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1771502895
"expiry_date" => null
]
16153 => array:7 [
"userID" => 16153
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1771586563
"expiry_date" => null
]
17086 => array:7 [
"userID" => 17086
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1771593610
"expiry_date" => null
]
2944 => array:7 [
"userID" => 2944
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1771603979
"expiry_date" => null
]
11706 => array:7 [
"userID" => 11706
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1771830238
"expiry_date" => null
]
17164 => array:7 [
"userID" => 17164
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1771839434
"expiry_date" => null
]
16758 => array:7 [
"userID" => 16758
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1771841082
"expiry_date" => null
]
15209 => array:7 [
"userID" => 15209
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1771855418
"date_request" => 1771855418
"expiry_date" => null
]
1131 => array:7 [
"userID" => 1131
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1771858146
"expiry_date" => null
]
17203 => array:7 [
"userID" => 17203
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1771861967
"expiry_date" => null
]
17224 => array:7 [
"userID" => 17224
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1771911357
"date_request" => 1771911357
"expiry_date" => null
]
813 => array:7 [
"userID" => 813
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1771940975
"date_request" => 1771940975
"expiry_date" => null
]
5038 => array:7 [
"userID" => 5038
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1771941027
"expiry_date" => null
]
15384 => array:7 [
"userID" => 15384
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1771952937
"date_request" => 1771952937
"expiry_date" => null
]
10260 => array:7 [
"userID" => 10260
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1772184756
"date_request" => 1772184756
"expiry_date" => null
]
14081 => array:7 [
"userID" => 14081
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1772185377
"date_request" => 1772185377
"expiry_date" => null
]
15303 => array:7 [
"userID" => 15303
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1772203175
"date_request" => 1772203175
"expiry_date" => null
]
17515 => array:7 [
"userID" => 17515
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1772212018
"date_request" => 1772212018
"expiry_date" => null
]
3971 => array:7 [
"userID" => 3971
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1772387687
"expiry_date" => null
]
13424 => array:7 [
"userID" => 13424
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1772444826
"expiry_date" => null
]
5132 => array:7 [
"userID" => 5132
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1772463214
"date_request" => 1772463214
"expiry_date" => null
]
6688 => array:7 [
"userID" => 6688
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1772548372
"date_request" => 1772548372
"expiry_date" => null
]
5995 => array:7 [
"userID" => 5995
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1772637093
"date_request" => 1772637093
"expiry_date" => null
]
1337 => array:7 [
"userID" => 1337
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1772651731
"expiry_date" => null
]
17827 => array:7 [
"userID" => 17827
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1772698923
"expiry_date" => null
]
17910 => array:7 [
"userID" => 17910
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1772702210
"expiry_date" => null
]
2783 => array:7 [
"userID" => 2783
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1772703910
"expiry_date" => null
]
17940 => array:7 [
"userID" => 17940
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1772718979
"expiry_date" => null
]
924 => array:7 [
"userID" => 924
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1772783705
"date_request" => 1772783705
"expiry_date" => null
]
18062 => array:7 [
"userID" => 18062
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1772790110
"expiry_date" => null
]
9480 => array:7 [
"userID" => 9480
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1772809597
"expiry_date" => null
]
17137 => array:7 [
"userID" => 17137
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1772810441
"date_request" => 1772810441
"expiry_date" => null
]
18132 => array:7 [
"userID" => 18132
"presence" => "in_person"
"status" => "declined"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1772815012
"expiry_date" => null
]
12201 => array:7 [
"userID" => 12201
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1773064496
"date_request" => 1773064496
"expiry_date" => null
]
6494 => array:7 [
"userID" => 6494
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1773064497
"date_request" => 1773064497
"expiry_date" => null
]
14400 => array:7 [
"userID" => 14400
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1773065209
"date_request" => 1773065209
"expiry_date" => null
]
18046 => array:7 [
"userID" => 18046
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773105740
"expiry_date" => null
]
4918 => array:7 [
"userID" => 4918
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773153217
"expiry_date" => null
]
7150 => array:7 [
"userID" => 7150
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773221987
"expiry_date" => null
]
6914 => array:7 [
"userID" => 6914
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1773227760
"date_request" => 1773227760
"expiry_date" => null
]
16901 => array:7 [
"userID" => 16901
"presence" => "in_person"
"status" => "declined"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773237452
"expiry_date" => null
]
2599 => array:7 [
"userID" => 2599
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773250668
"expiry_date" => null
]
13010 => array:7 [
"userID" => 13010
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1773349012
"date_request" => 1773349012
"expiry_date" => null
]
10501 => array:7 [
"userID" => 10501
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1773395264
"date_request" => 1773395264
"expiry_date" => null
]
18870 => array:7 [
"userID" => 18870
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773413442
"expiry_date" => null
]
14181 => array:7 [
"userID" => 14181
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773567198
"expiry_date" => null
]
7263 => array:7 [
"userID" => 7263
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1773606074
"date_request" => 1773606074
"expiry_date" => null
]
18692 => array:7 [
"userID" => 18692
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773644562
"expiry_date" => null
]
17263 => array:7 [
"userID" => 17263
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773656696
"expiry_date" => null
]
19214 => array:7 [
"userID" => 19214
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773733592
"expiry_date" => null
]
9862 => array:7 [
"userID" => 9862
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773736025
"expiry_date" => null
]
17080 => array:7 [
"userID" => 17080
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773744096
"expiry_date" => ""
]
16088 => array:7 [
"userID" => 16088
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1773755105
"date_request" => 1773755105
"expiry_date" => null
]
16514 => array:7 [
"userID" => 16514
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773756540
"expiry_date" => null
]
17930 => array:7 [
"userID" => 17930
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773764318
"expiry_date" => null
]
17791 => array:7 [
"userID" => 17791
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1774135913
"date_request" => 1773786811
"expiry_date" => null
]
15773 => array:7 [
"userID" => 15773
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1773797115
"date_request" => 1773797115
"expiry_date" => null
]
19447 => array:7 [
"userID" => 19447
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1774345334
"date_request" => 1773826354
"expiry_date" => null
]
19463 => array:7 [
"userID" => 19463
"presence" => "in_person"
"status" => "declined"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773830236
"expiry_date" => null
]
19465 => array:7 [
"userID" => 19465
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773830736
"expiry_date" => null
]
19473 => array:7 [
"userID" => 19473
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773837644
"expiry_date" => null
]
11817 => array:7 [
"userID" => 11817
"presence" => "in_person"
"status" => "declined"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773842434
"expiry_date" => null
]
4871 => array:7 [
"userID" => 4871
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773843181
"expiry_date" => null
]
11629 => array:7 [
"userID" => 11629
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773856436
"expiry_date" => null
]
19627 => array:7 [
"userID" => 19627
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773901937
"expiry_date" => null
]
19650 => array:7 [
"userID" => 19650
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1773914784
"expiry_date" => null
]
10214 => array:7 [
"userID" => 10214
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1773937724
"date_request" => 1773937724
"expiry_date" => null
]
10071 => array:7 [
"userID" => 10071
"presence" => "in_person"
"status" => "declined"
"paw_networking" => "on"
"paw_networking_timestamp" => 1773940866
"date_request" => 1773940866
"expiry_date" => null
]
13198 => array:7 [
"userID" => 13198
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1774005406
"date_request" => 1774005406
"expiry_date" => null
]
19896 => array:7 [
"userID" => 19896
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1774017968
"expiry_date" => null
]
1545 => array:7 [
"userID" => 1545
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1774046571
"expiry_date" => null
]
15123 => array:7 [
"userID" => 15123
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1774094707
"date_request" => 1774094707
"expiry_date" => null
]
18533 => array:7 [
"userID" => 18533
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1774100014
"expiry_date" => ""
]
1892 => array:7 [
"userID" => 1892
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => ""
"paw_networking_timestamp" => ""
"date_request" => 1774207300
"expiry_date" => null
]
17034 => array:7 [
"userID" => 17034
"presence" => "in_person"
"status" => "accepted"
"paw_networking" => "on"
"paw_networking_timestamp" => 1774209684
"date_request" => 1774209684
"expiry_date" => null
]
]
+"stats": {#4588
+"total": "60"
+"accepted": 58
+"pending": 0
+"declined": 17
+"cancelled": 0
+"waiting": 0
+"in_person": 58
+"online": 0
+"checked_in": 0
+"left": 2
}
}
]
"__env" => Illuminate\View\Factory {#2419}
"app" => Illuminate\Container\Container {#2401}
"override" => "app"
"display_sidebar" => false
"notices" => []
"browser" => null
"displayArchiveStructs" => false
"relatedEdition" => WP_Post {#4155}
"edition_dates" => "23 - 27 March 2026"
"static_pages" => array:9 [
"middle_office" => "89"
"digital_library" => "13219"
"legal_notice" => "955"
"privacy_statement" => "12766"
"contact_us" => "95"
"sign_in" => "424"
"visitor_register" => "40592"
"partner_register" => "28"
"maintenance" => "40491"
]
"user" => WP_User {#4150}
"currentEvents" => array:1 [
0 => 41365
]
"previousEvents" => []
"partner" => WP_Post {#4583}
"link" => "https://parisarbitrationweek.preprod.online/partner/diales/"
"__currentLoopData" => array:1 [
0 => 41365
]
"logo" => "https://parisarbitrationweek.preprod.online/wp-content/uploads/2025/02/diales-new-logo_no-tagline-01-1-2087x875_1209.png"
"loop" => null
"eventID" => 41365
"event" => WP_Post {#4579}
]
